Real Estate (Regulation and Development) Act 2016 RERA
#1

The Real Estate (Regulation and Development) Act, 2016 RERA will finally give India’s real estate sector its first regulator from Monday, May 1, 2016. RERA was passed by parliament last year and the Union Ministry of Housing and Urban Poverty Alleviation had given time till May 1, 2017, to formulate and notify rules for the functioning of the regulator. RERA seeks to bring clarity and fair practices that would protect the interests of buyers and also impose penalties on errant builders.



RERA is applicable for 

1. the real estate project on land more than 500 sq. m. or project having more than eight 8 residential units

2. Projects which do not have completion certificate before commencement of Act. 


For more information click

Real Estate (Regulation and Development) Act 2016

Manish Jain Luhadia 
B.Arch (hons.), M.Plan
Email: manish@frontdesk.co.in
Tel: +91 141 6693948
Reply
#2

Government of India has enacted the Real Estate (Regulation and Development) Act 2016 and all the provisions of the Act have came into force with effect from May 1, 2017. Under this Act, Government of Rajasthan has notified the Rules namely Rajasthan Real Estate (Regulation and Development) Rules, 2017. 

The State Government, vide its Order dt.17.02.2017 as designated the Additional Chief Secretary, Urban Development and Housing Department as the Real State Regulatory Authority until the establishment of a Real Estate Regulatory Authority (Rajasthan RERA). 

Similarly the State Government  vide Notification dated 15.05.2017 has designated the Food Safety Appellate Tribunal as the Real Estate Appellate Tribunal until the establishment of Real Estate Appellate Tribunal under the Act.

Front Desk Architects
www.frontdesk.co.in
Email: architect@frontdesk.co.in , Tel: +91 0141 6693948
Reply
#3

RAJASTHAN REAL ESTATE REGULATORY AUTHORITY 

RERA website link http://rera-rajasthan.in

RERA Act  http://rera-rajasthan.in/Content/pdf/Rea...t_2016.pdf

RERA Rule http://rera-rajasthan.in/Content/pdf/RER...s_2017.pdf


The key components of Real Estate (Regulation and Development) Act, 2016 are as follows:


1. Real Estate Regulatory Authority

Under this Act, State Government is required to establish Real Estate Regulatory Authority for regulation and promotion of the real estate sector in the State. The Authority shall strive to facilitate the growth and promotion of a healthy, transparent, efficient and competitive real estate sector while protecting the interest of allottees, promoters and real estate agents. The authority shall also establish an adjudicating mechanism for speedy dispute redressal regarding registered real estate projects. The key responsibilities of the Authority shall be as follows:

Ensuring Disclosures of Real Estate Projects by Promoters
Real Estate Projects Registration
Real Estate Agents Registration
Complaints Redressal
Provide recommendations to appropriate Government on in matters relating to the development & promotion of real estate sector;

2. Real Estate Appellate Tribunal

The State Government is required also to establish Appellate Tribunal to hear appeals from the decisions, directions or orders of the Real Estate Regulatory Authority and Adjudicating Officer. Any person aggrieved by any direction or decision or order made by the Authority or by an adjudicating officer may file an appeal before the Appellate Tribunal and the appeal shall be dealt with by it as expeditiously as possible and endeavour shall be made by it to dispose of the appeal within a period of sixty days.

3. Real Estate Projects Registration

All commercial and residential real estate projects will have to register except in projects where

area of land proposed to be developed does not exceed five hundred square meters
number of apartments proposed to be developed does not exceed eight inclusive of all phases
promoter has received completion certificate for a real estate project prior to commencement of this Act
for the purpose of renovation or repair or re-development which does not involve marketing, advertising selling or new allotment of any apartment, plot or building, as the case may be, under the real estate project
No promoter shall advertise, market, book, sell or offer for sale, or invite persons to purchase in any manner any plot, apartment or building, as the case may be, in any real estate project or part of it, in any planning area within Rajasthan, without registering the real estate project with the Rajasthan Real Estate Regulatory Authority. Promoter of ongoing real estate projects, in which all buildings as per sanctioned plan have not completed, shall also be required to be registered for such phase of the project.

If any promoter fails to register as per Act, he shall be liable to a penalty which may extend up to ten per cent of the estimated cost of the real estate project. On continued violation, he shall be punishable with imprisonment for a term which may extend up to three years or with fine which may extend up to a further ten per cent of the estimated cost of the real estate project, or with both.

Apart from Registration, the promoters shall be required to provide quarterly updates on the status of the project to the Authority.


4. Real Estate Agents Registration

All Real Estate Agents should register under this Act. No real estate agent shall facilitate the sale or purchase of or act on behalf of any person to facilitate the sale or purchase of any plot, apartment or building, as the case may be, in a real estate project or part of it, without obtaining registration under this section.

If any real estate agent fails to register, he shall be liable to a penalty of ten thousand rupees for every day during which such default continues, which may cumulatively extend up to five per cent of the cost of plot, apartment or buildings, as the case may be, of the real estate project, for which the sale or purchase has been facilitated

5. Filing of complaints

Any aggrieved person may file a complaint with Rajasthan RERA or the Adjudicating Officer, as the case may be, with respect to any registered real estate project, for any violation or contravention of the provisions of this Act or the rules and regulations made there under. The Authority shall establish an adjudicating mechanism for speedy redressal of such complaints.

Any person aggrieved by any direction or decision or order made by Rajasthan RERA or by an Adjudicating Officer may file an appeal before the Appellate Tribunal

Any person aggrieved by any decision or order of the Appellate Tribunal, may file an appeal to the High Court

6. Financial Discipline

The Act strives to ensure greater financial discipline in the real estate sector. Some of its provisions are as follows:

A promoter shall not accept more than ten per cent of the cost of the apartment, plot, or building as the case may be, as an advance payment or an application fee, from a person without first entering into a written agreement for sale (in prescribed Form-G) with such person and register the said agreement for sale
Seventy per cent of the amounts realized for the real estate project from the allottees, from time to time, shall be deposited in a separate account to be maintained in a scheduled bank to cover the cost of construction and the land cost and shall be used only for that purpose
Withdrawal from such accounts shall be in proportion to the percentage of completion of the project, which shall be certified by an engineer, an architect and a chartered accountant in practice.
Promoter to compensate buyer for any false or incorrect statement with full refund of property cost with interest
Project Accounts to be Audited / FY. Copy to be submitted to Rajasthan RERA
Provision for Rajasthan RERA to freeze project bank account upon non-compliance
Provisions for stronger financial penalties for non-compliances of Real Estate Regulatory Authority.

7. Transparency

The Act shall drive great transparency in the real estate sector as follows:

Details of all the Registered Projects shall be available online for citizens including:
sanctioned plans, layout plans, along with specifications, approved by the competent authority
Proposed Plan, Proposed Layout Plan of the whole project and Floor Space Index proposed to be consumed in the whole project, as proposed by the promoter
Proposed Number of building(s) or wing(s) to be constructed and sanctioned number of the building(s) or wing(s).
the stage wise time schedule of completion of the project, including the provisions for civic infrastructure like water, sanitation and electricity.
quarterly update of the list of number and types of apartments or plots, as the case may be, booked
quarterly update of the list of number of covered parking, garages booked;
quarterly update of the list of approvals taken and the approvals which are pending subsequent to commencement certificate;
quarterly update of the status of the project; and
such other information and documents as may be specified by the regulations made by Rajasthan RERA.
The advertisement or prospectus issued or published by the promoter shall mention prominently the website address of Rajasthan RERA, wherein all details of the registered project have been entered and include the registration number obtained from the Authority

8. Citizen Centricity

Citizens shall be able to view, on Rajasthan RERA website, all disclosures pertaining to registered projects. This shall enable data driven informed decision making.
Promoter cannot make any additions and alterations in the sanctioned plans, layout plans and specifications and the nature of fixtures, fittings and amenities etc. without the previous consent of at least two-thirds of the allottees, other than the promoter, who have agreed to take apartments in such building.
If the promoter fails to complete or is unable to give possession of an apartment, plot or building, in accordance with the terms of the agreement for sale, he shall be liable to pay interest for every month of delay. Further, in case the allottee wishes to withdraw from the project, without prejudice to any other remedy available, to return the amount received by him with interest
Promoter to enable formation of Legal Entity like Cooperative Society, Company, Association, Federation etc. within three months from the date on which sixty per cent of the total number of Purchasers in such a building or a wing, have booked their apartment.
Promoter shall execute a registered conveyance deed in favour of the allottee within three months from date of issue of occupancy certificate or sixty per cent of the total number of Purchasers in such a building or a wing, have paid the full consideration to the promoter, whichever is earlier.

9. Refund


In case a promoter applies for withdrawal of application of the Project before the expiry of the period of thirty days, registration fee to the extent of 5% paid or Rs. 25,000/- whichever is more shall be retained by the Authority and the remaining amount shall be refunded .Similarly in case of rejection of application for, registration of a Project or registration of a Real Estate Agent or extension of registration of a Project or renewal of registration of Real Estate Agent, registration fee to the extent of 5% paid or Rs. 25,000/- whichever is more shall be retained by the Authority and the remaining amount shall be refunded.  
Real Estate (Regulation and Development) Act 2016 is a step towards reforming the real estate sector in India, encouraging greater transparency, citizen centricity, accountability and financial discipline.

Front Desk Architects
www.frontdesk.co.in
Email: architect@frontdesk.co.in , Tel: +91 0141 6693948
Reply


Forum Jump:


Users browsing this thread: 1 Guest(s)